Tag Archives: Liquidated Damages

Merit Decision: Court Upholds Liquidated Damages Provision in Public Works Construction Contract. Boone Coleman Constr., Inc. v. Piketon.

On February 24, 2016, the Supreme Court of Ohio handed down a merit decision in Boone Coleman Constr., Inc. v. Piketon, 2016-Ohio-628. In a fractured 6-1 opinion authored by Chief Justice O’Connor, the court upheld a contractual liquidated-damages provision … Continue reading

Posted in Contracts, Damages, Merit Decisions, Ohio Supreme Court Watch | Tagged , , |

What’s On Their Minds: Liquidated Damages or Penalty in Public Construction Contract? Boone Coleman Construction Co., Inc. v. Village of Piketon, Ohio.

Update: On February 24, 2016, the Supreme Court of Ohio handed down a merit decision in this case.  Read the analysis here.

“Is this a big problem in the construction area? I don’t see a whole host of … Continue reading

Posted in Contracts, Damages, Ohio Supreme Court Watch, Student Contributors, What's On Their Minds? | Tagged , , |

Oral Argument Preview: Liquidated Damages or Penalty in Public Construction Contract? Boone Coleman Construction Co., Inc. v. Village of Piketon, Ohio.

Update: On February 24, 2016, the Supreme Court of Ohio handed down a merit decision in this case.  Read the analysis here.

Read the analysis of the oral argument here.

On June 9, 2015, the Supreme Court … Continue reading

Posted in Contracts, Damages, Ohio Supreme Court Watch, Oral Argument Preview, Student Contributors | Tagged , , |